Examines the impact of the decision of the California Supreme Court in the case Kiewit versus Pasadena School District on the administration of California construction contracts. Features of the construction contract under the case; Effects on notice conditions in building contracts; Provision applied by the court in the case to invalidate the right of a contractor to claim an extension of time for delays beyond his control.

Included in

Law Commons



To view the content in your browser, please download Adobe Reader or, alternately,
you may Download the file to your hard drive.

NOTE: The latest versions of Adobe Reader do not support viewing PDF files within Firefox on Mac OS and if you are using a modern (Intel) Mac, there is no official plugin for viewing PDF files within the browser window.